Loading...
HomeMy WebLinkAboutItem No. 06 Final Map No. 31957 & Agreements with Sam-Running Deer, LLCCity Council Agenda Report City of Lake Elsinore 130 South Main Street Lake Elsinore, CA 92530 www.lake-elsinore.org File Number: ID# 19-706 Agenda Date: 8/25/2020 Status: Approval FinalVersion: 1 File Type: Council Consent Calendar In Control: City Council / Successor Agency Agenda Number: 6) Final Map No. 31957 and Agreements with Sam-Running Deer, LLC 1.Approve Final Map No. 31957 subject to the City Engineer’s acceptance as being true and correct; 2.Authorize the City Manager to execute the Agreements for Construction of Improvements and Monumentation with Sam-Running Deer, LLC; and 3.Authorize the City Clerk to sign and arrange for the recordation of Final Map No. 31957. Page 1 City of Lake Elsinore Printed on 8/20/2020 Page 1 REPORT TO CITY COUNCIL To: Honorable Mayor and Members of the City Council From: Grant Yates, City Manager Prepared by: Rita Thompson, Senior Engineering Technician Date: August 25, 2020 Subject: Final Map No. 31957 and Agreements with Sam-Running Deer, LLC Recommendations 1. Approve Final Map No. 31957 subject to the City Engineer’s acceptance as being true and correct; 2. Authorize the City Manager to execute the Agreements for Construction of Improvements and Monumentation with Sam-Running Deer, LLC; and 3. Authorize the City Clerk to sign and arrange for the recordation of Final Map No. 31957. Background The proposed Final Map No. 31957 is located northerly of Lincoln Street and westerly of Running Deer and Mountain Street. It consists of 34.2 acres. Included are 97 residential lots, 4 lettered lots (3 lots for dedicated open space, 1 lot for water quality basin) and 3 lots for public right of way. The average lot size is 7,673 square feet, with the smallest being 6,000 square feet. (Exhibits A and B) The proposed streets will be public and the landscaping/wall maintenance will be provided by a Home Owners Association. Project public improvements include the extension of Lincoln, Mountain and Running Deer Streets, local residential streets and installation of storm drain system. All future public improvements will be secured upon City Council acceptance of Bonds and approval and City execution of the modified Agreements for Construction of Improvements and Monumentation (Exhibits C and D). Discussion Per the Subdivision Map Act section 66474.1, the Final Map has been reviewed and it has been determined that it is in substantial conformance to the previously approved Tentative Tract Map No. 31957. All Conditions of Approval relative to the Final Map approval have been completed. The Agreement modifications (highlighted on Exhibits C and D) consist of; 1) extension of construction period from one to two years, and 2) the addition of a force majeure section. The Final Map 31957, Running Deer August 25, 2020 Page 2 modifications were made at the request of the developer and have been reviewed and approved by the City Attorney. They were made to allow for project delays resulting from constraints due to the COVID-19 pandemic. Bonds have been secured based on City review and approval of engineer’s signed and sealed cost estimates. Fiscal Impact Public improvements are to be constructed by the developer. The surety posted is sufficient for the City to complete the construction if needed. Staff time was utilized to prepare the documents. Exhibits A. Index Map B. Vicinity Map C. Improvement Agreement D. Monumentation Agreement TRACT MAP NO. 31957 VICINITY MAP TRACT MAP 31957 https://lakeelsinore.sharepoint.com/eng/Shared Documents/Engr/Correspondence/TR 31957/Mapping/City Council TMP 19-895/TR 31957_Exhibit C_Agreement_Improvements.doc 1 AGREEMENT FOR CONSTRUCTION OF IMPROVEMENTS WHEREAS, the undersigned . . whose business address is . , herein referred to as "Subdivider", has submitted to the City of Lake Elsinore for its approval a Final Map of a subdivision designated as TR 31957 which map was prepared by K & A Engineering, Inc. ; and, WHEREAS, the Subdivider has not completed all the work, or made all of the improvements required by Title 16, Lake Elsinore Municipal Code or such other ordinances of the City of Lake Elsinore requiring construction of improvements in conjunction with land divisions, subdivisions, and the like, hereinafter collectively referred to as "said ordinance"; and, WHEREAS, Subdivider desires to enter into an agreement providing for the completion of the work and the making of the improvements and to furnish security for the performance of this agreement in accordance with the provisions of said ordinance; NOW, THEREFORE, in consideration of the approval of said Final Map by the City, and as a condition of such approval, the Subdivider promises and agrees at his own expense to do all of the work and make all of the improvements required by said ordinance, which work and improvements, without limitation by enumeration, consists of: Street and Storm Drain Improvements pursuant to approved plans sets 07-0143 – 155, 07-176 – 182, and 17-342 – 343 . The above enumeration of items is understood to be only a general designation of the work and improvements, and not a binding description thereof. All of said work shall be done and improvements made and completed which are shown on and in strict compliance with applicable plans and specifications, and any subsequent alterations thereto, which alterations in said plans and specifications and the work to be performed may be accomplished without first giving prior notice thereof to the surety; provided, however in the event the estimated cost of any changes or alterations in said work exceeds ten percent (10%) of the original estimated cost of the improvements, then the consent of the surety shall be obtained, and absent such consent, the surety's obligations shall not then exceed the cost of improvements to be constructed under the said originally approved plans prior to said alterations; provided, further, in no event shall such change result in exonerating the surety's obligations. Such work shall be completed and improvements m ade within two years from the date of this agreement, unless such time be extended by the City upon written application of the Subdivider. https://lakeelsinore.sharepoint.com/eng/Shared Documents/Engr/Correspondence/TR 31957/Mapping/City Council TMP 19-895/TR 31957_Exhibit C_Agreement_Improvements.doc 2 Failure to make such written request shall not preclude the City from extending this agreement. In the absence of written notice by the City to the Developer that the agreement has been terminated, said agreement shall remain in effect. It is understood that by providing security for this agreement, the surety consents in advance to any extension of time as may be given by the City to the Subdivider and waives notices of such extension. The making of an application for an extension of time by the Subdivider shall, upon the granting of the application by the City, constitute a waiver by the Subdivider and by the surety of all defenses of laches, estoppel, statutes of limitations, and other limitations of action in any action or proceeding filed by the City. Anything in this agreement to the contrary notwithstanding, the dates by which Subdivider must complete the improvements shall be extended on a day-for-day basis to the extent Subdivider is unable to complete the same due to Force Majeure/COVID-19. As used in this Agreement, “Force Majeure” means strikes, lockouts, labor disputes, acts of God, fire, earthquake, flood or other casualty, shortages of labor or materials, war, terrorist acts, pandemics, civil disturbances and other causes (other than financial inability) beyond the reasonable control of the performing party. Further, and without limiting the Force Majeure protections of this agreement, Subdivider and City recognize and acknowledge that due to current and potential disruptions arising out of the novel coronavirus, COVID-19, Subdivider may be unable to complete the improvements pursuant to this agreement within the allotted two years due to known and/or reasonably anticipated events outside of the reasonable control of Subdivider, including, without limitation, (a) closure of or reduced staffing in governmental offices resulting in delays in approval of plans and specifications for the improvements, issuance of permits for the improvements, and required inspections of the improvements, (b) delays in preparation of the plans, specifications and other required submittals by Subdivider’s engineer due to governmental office closures and shortages of labor, (c) delays in completion of the improvements occasioned by shortages of construction labor and/or shortages of or delays in delivery of construction materials, or (d) current or future laws, ordinances or orders (whether local, state or federal) which restrict or prohibit Subdivider or its contractors from completing the improvements or any portion thereof (each, a “COVID-19 Delay”). In the event performance of the improvements is delayed due to COVID-19 Delay, Subdivider shall: (1) provide prompt written notice to City of such COVID-19 Delay: (2) indicate to City the best estimated time for resolution or propose an alternative solution, and (3) continue to exercise commercially reasonable efforts to resolve the applicable COVID-19 Delay. The parties acknowledge that one or more COVID-19 Delays may occur and that, following Subdivider’s notice to City of a COVID-19 Delay, the deadline by which to complete the improvements shall be extended by the estimated duration of the COVID-19 Delay, and such extension shall be subject to change based on the actual duration of the COVID-19 Delay as reasonably determined by Subdivider at the time such COVID-19 Delay ceases. By way of example only, if https://lakeelsinore.sharepoint.com/eng/Shared Documents/Engr/Correspondence/TR 31957/Mapping/City Council TMP 19-895/TR 31957_Exhibit C_Agreement_Improvements.doc 3 Subdivider estimates delay of fifteen (15) days in obtaining building permits for the improvements and reasonably anticipates that any applicable laws, ordinances or orders restricting construction activities will delay the date on which the improvements are complete by an additional thirty (30) days, then the deadline to complete the improvements shall be extended for forty-five (45) days, subject to modification based on the actual duration of such delays. The Subdivider further agrees that any and all grading done or to be done in conjunction with the development in the herein described Final Map shall conform to the requirements of the Lake Elsinore Municipal Code and any other applicable ordinances regulating excavations and fills (e.g., grading regulations) and shall be completed within the period of time described above and prior to the acceptance by or on behalf of the City of the work and improvements and prior to the release by the City of the surety guaranteeing performance of this agreement, in order that said improvements will not be endangered by improper drainage or other hazards. The Subdivider promises and agrees to maintain all of the improvements to be constructed under this contract in a state of good repair, until all of the work and improvements are completed and accepted by or on behalf of the City and until the security for the performance of this agreement is released. Said maintenance shall include, but shall not be limited to, repair of pavement, curbs, gutters, sidewalks, parkways, sewers, and removal of debris from sewers and storm drains; said maintenance shall also include, but not be limited by this enumeration, sweeping, repairing and maintaining in good and safe condition all streets and street improvements. It shall be the Subdivider's responsibility to initiate this work but if he should fail to do so, he shall promptly perform such maintenance when notified to do so by the City Engineer of the City of Lake Elsinore. Upon failure of the Subdivider to properly maintain, the City may do all necessary work required by this paragraph, the cost thereof being chargeable to the Subdivider and his surety under this agreement. The Subdivider further agrees under this agreement to hold the City and its officers and employees free and harmless from any claim s, demand or action for damages, injury or death, and to indemnify the City for any loss, arising out of or incurred as the result of or in connection with improper maintenance or dangerous conditions or any act or omission in connection with any of the maintenance activities required under this paragraph, existing or occurring or arising out of any act or omission occurring prior to final acceptance by the City of all the work and improvements constructed under this contract. The Subdivider shall be responsible for maintaining all improvements for a period of one year following completion of the work and acceptance by the City against any defective work or labor done, or defective materials furnished in the performance of the contract, and it is further agreed that upon completion and acceptance of the improvements by the City of Lake Elsinore, the liability of the surety for no less than ten percent (10%) of the face amount thereof or $300.00, whichever is greater, will continue for the purpose of guaranteeing maintenance of the improvements for a period of one year following the completion and https://lakeelsinore.sharepoint.com/eng/Shared Documents/Engr/Correspondence/TR 31957/Mapping/City Council TMP 19-895/TR 31957_Exhibit C_Agreement_Improvements.doc 4 acceptance by the City against any defective work or labor done, or defective materials furnished in the performance of this contract with the City of Lake Elsinore. If the Subdivider and the surety fail to install all or any part of the improvements required by this agreement within the time set forth herein, or fail to comply with any other obligation contained herein, they shall be jointly and severally liable to the City for any administrative expenses and attorney's fees incurred in obtaining compliance with this agreement and any such expenses and fees incurred in processing any action for damages or for any other remedies permitted by law. It is further understood and agreed that upon default of any obligation hereunder, and at any time after any such default, the City may make written demand upon the Subdivider and surety to immediately remedy the default or complete the work. If said remedial activities or completion of work are not commenced within sixty (60) days after such demand is made and are not thereafter diligently prosecuted to completion and fully completed within one hundred twenty (120) days after the making of such demand (or such other time as may be contained in said demand), the City may then complete or arrange for completion of all remaining work or conduct such remedial activity as in the sole judgement of the City may be required, all at the full expense and obligation of the Subdivider and surety and all without the necessity of giving any further notice to the Subdivider or surety before the City performs or arranges for performance of any remaining work or improvements, and whether or not the Subdivider or surety have constructed any of the required improvements at the time. In the event the City elects to complete or arrange for completion of remaining work and improvements, the City Engineer, upon such election, may require all work by the Subdivider or surety to cease in order to permit adequate coordination by the City for completing any remaining work and improvements not yet completed. It is agreed that all work and improvements done pursuant to this agreement shall conform to the standards applicable at the time work is actually commenced. The Subdivider shall provide security in the amount of Three Million Five Hundred Forty-Seven Thousand One Hundred Two and 58/100th Dollars ($3,547,102.58 ) to guarantee the performance of this agreement. In addition, the Subdivider shall provide security in the amount of Three Million Five Hundred Forty-Seven Thousand One Hundred Two and 58/100th Dollars ($3,547,102.58 ) to guarantee payment to any contractors, subcontractors, and persons furnishing labor, materials and equipment to them for the performance of the work herein described. Said security shall be in the form of a Surety Bond (corporate surety bonds, cash deposits, etc.) The Subdivider acknowledges and agrees to City regulations governing signs and advertising structures. Subdivider agrees and consents to removal by the City of all signs erected, placed, or situated in https://lakeelsinore.sharepoint.com/eng/Shared Documents/Engr/Correspondence/TR 31957/Mapping/City Council TMP 19-895/TR 31957_Exhibit C_Agreement_Improvements.doc 5 violation of any City ordinance governing size, location, or required permits. Removal shall be at the expense of the Subdivider and Subdivider shall indemnify and hold the City free and harmless from any claim or demand arising out of or incurred as a result of such removal, excepting negligent acts or omissions by the City, its agents or employees. Subdivider agrees that said signs may be erected only pursuant to a permit issued by the City upon payment of necessary fees or deposits. The Subdivider agrees to provide to the City a Public Liability Insurance Policy, making the City of Lake Elsinore, its officers, agents and employees, additional insured against any injuries or death to any person and property damage. The amount and the insurance company must be approved by the City Engineer. In addition, the Subdivider shall deposit a copy of the Workmen's Compensation Insurance coverage by an approved insurance company and in an amount satisfactory to the City, and as required by law. For purposes of enforcing this agreement, the term "City" includes the City Council, the City Manager, the City Attorney, City Engineer, or any of them, or any of their authorized representatives. In WITNESS WHEREOF, the Subdivider has caused this agreement to be executed this day of , 2020. SIGNED: _________________________________________ (Type Name/Title) FOR: ______________________________________________ (Name of Company on above line) CITY OF LAKE ELSINORE BY: __________________________________________ Grant M Yates, City Manager CITY OF LAKE ELSINORE ATTEST: _________________________________________ Candice Alvarez, City Clerk CITY OF LAKE ELSINORE https://lakeelsinore.sharepoint.com/eng/Shared Documents/Engr/Correspondence/TR 31957/Mapping/Monumentation/Construction Agreement_Monumentation_rev.doc 1 AGREEMENT FOR CONSTRUCTION OF IMPROVEMENTS WHEREAS, the undersigned SAM-Running Deer, LLC . whose business address is 2911 Tennyson Avenue, Suite 400, Eugene, OR 97408 . , herein referred to as "Subdivider", has submitted to the City of Lake Elsinore for its approval a Final Map of a subdivision designated as TR 31957 which map was prepared by K & A Engineering, Inc. ; and, WHEREAS, the Subdivider has not completed all of the work, or made all of the improvements required by Title 16, Lake Elsinore Municipal Code or such other ordinances of the City of Lake Elsinore requiring construction of improvements in conjunction with land divisions, subdivisions, and the like, hereinafter collectively referred to as "said ordinance"; and, WHEREAS, Subdivider desires to enter into an agreement providing for the completion of the work and the making of the improvements and to furnish security for the performance of this agreement in accordance with the provisions of said ordinance; NOW, THEREFORE, in consideration of the approval of said Final Map by the City, and as a condition of such approval, the Subdivider promises and agrees at his own expense to do all of the work and make all of the improvements required by said ordinance, which work and improvements, without limitation by enumeration, consists of: installation of monumentation shown on sheet 2 of 9 of Final Map 31957 . The above enumeration of items is understood to be only a general designation of the work and improvements, and not a binding description thereof. All of said work shall be done and improvements made and completed which are shown on and in strict compliance with applicable plans and specifications, and any subsequent alterations thereto, which alterations in said plans and specifications and the work to be performed may be accomplished without first giving prior notice thereof to the surety; provided, however in the event the estimated cost of any changes or alterations in said work exceeds ten percent (10%) of the original estimated cost of the improvements, then the consent of the surety shall be obtained, and absent such consent, the surety's obligations shall not then exceed the cost of improvements to be constructed under the said originally approved plans prior to said alterations; provided, further, in no event shall such change result in exonerating the surety's obligations. Such work shall be completed and improvements made within two years from the date of this agreement, unless such time be extended by the City upon written application of the Subdivider. https://lakeelsinore.sharepoint.com/eng/Shared Documents/Engr/Correspondence/TR 31957/Mapping/Monumentation/Construction Agreement_Monumentation_rev.doc 2 Failure to make such written request shall not preclude the City from extending this agreement. In the absence of written notice by the City to the Developer that the agreement has been terminated, said agreement shall remain in effect. It is understood that by providing security for this agreement, the surety consents in advance to any extension of time as may be given by the City to the Subdivider and waives notices of such extension. The making of an application for an extension of time by the Subdivider shall, upon the granting of the application by the City, constitute a waiver by the Subdivider and by the surety of all defenses of laches, estoppel, statutes of limitations, and other limitations of action in any action or proceeding filed by the City. Anything in this agreement to the contrary notwithstanding, the dates by which Subdivider must complete the improvements shall be extended on a day-for-day basis to the extent Subdivider is unable to complete the same due to Force Majeure/COVID-19. As used in this Agreement, “Force Majeure” means strikes, lockouts, labor disputes, acts of God, fire, earthquake, flood or other casualty, shortages of labor or materials, war, terrorist acts, pandemics, civil disturbances and other causes (other than financial inability) beyond the reasonable control of the performing party. Further, and without limiting the Force Majeure protections of this agreement, Subdivider and City recognize and acknowledge that due to current and potential disruptions arising out of the novel coronavirus, COVID-19, Subdivider may be unable to complete the improvements pursuant to this agreement within the allotted two years due to known and/or reasonably anticipated events outside of the reasonable control of Subdivider, including, without limitation, (a) closure of or reduced staffing in governmental offices resulting in delays in approval of plans and specifications for the improvements, issuance of permits for the improvements, and required inspections of the improvements, (b) delays in preparation of the plans, specifications and other required submittals by Subdivider’s engineer due to governmental office closures and shortages of labor, (c) delays in completion of the improvements occasioned by shortages of construction labor and/or shortages of or delays in delivery of construction materials, or (d) current or future laws, ordinances or orders (whether local, state or federal) which restrict or prohibit Subdivider or its contractors from completing the improvements or any portion thereof (each, a “COVID-19 Delay”). In the event performance of the improvements is delayed due to COVID-19 Delay, Subdivider shall: (1) provide prompt written notice to City of such COVID-19 Delay: (2) indicate to City the best estimated time for resolution or propose an alternative solution, and (3) continue to exercise commercially reasonable efforts to resolve the applicable COVID-19 Delay. The parties acknowledge that one or more COVID-19 Delays may occur and that, following Subdivider’s notice to City of a COVID-19 Delay, the deadline by which to complete the improvements shall be extended by the estimated duration of the COVID-19 Delay, and such extension shall be subject to change based on the actual duration of the COVID-19 Delay as reasonably determined by Subdivider at the time such COVID-19 Delay ceases. By way of example only, if Subdivider estimates delay of fifteen (15) days in obtaining building permits for the improvements and reasonably anticipates that any applicable laws, ordinances or orders restricting construction activities will delay the date on which the improvements are complete by an additional thirty (30) days, then the deadline to complete the improvements https://lakeelsinore.sharepoint.com/eng/Shared Documents/Engr/Correspondence/TR 31957/Mapping/Monumentation/Construction Agreement_Monumentation_rev.doc 3 shall be extended for forty-five (45) days, subject to modification based on the actual duration of such delays. The Subdivider further agrees that any and all grading done or to be done in conjunction with the development in the herein described Final Map shall conform to the requirements of the Lake Elsinore Municipal Code and any other applicable ordinances regulating excavations and fills (e.g., grading regulations) and shall be completed within the period of time described above and prior to the acceptance by or on behalf of the City of the work and improvements and prior to the release by the City of the surety guaranteeing performance of this agreement, in order that said improvements will not be endangered by improper drainage or other hazards. The Subdivider promises and agrees to maintain all the improvements to be constructed under this contract in a state of good repair, until all of the work and improvements are completed and accepted by or on behalf of the City and until the security for the performance of this agreement is released. Said maintenance shall include, but shall not be limited to, repair of pavement, curbs, gutters, sidewalks, parkways, sewers, and removal of debris from sewers and storm drains; said maintenance shall also include, but not be limited to by this enumeration, sweeping, repairing and maintaining in good and safe condition all streets and street improvements. It shall be the Subdivider's responsibility to initiate this work but if he should fail to do so, he shall promptly perform such maintenance when notified to do so by the City Engineer of the City of Lake Elsinore. Upon failure of the Subdivider to properly maintain, the City may do all necessary work required by this paragraph, the cost thereof being chargeable to the Subdivider and his surety under this agreement. The Subdivider further agrees under this agreement to hold the City and its officers and employees free and harmless from any claims, demand or action for damages, injury or death, and to indemnify the City for any loss, arising out of or incurred as the result of or in connection with improper maintenance or dangerous conditions or any act or omission in connection with any of the maintenance activities required under this paragraph, existing or occurring or arising out of any act or omission occurring prior to final acceptance by the City of all the work and improvements constructed under this contract. The Subdivider shall be responsible for maintaining all improvements for a period of one year following completion of the work and acceptance by the City against any defective work or labor done, or defective materials furnished in the performance of the contract, and it is further agreed that upon completion and acceptance of the improvements by the City of Lake Elsinore, the liability of the surety for no less than ten percent (10%) of the face amount thereof or $300.00, whichever is greater, will continue for the purpose of guaranteeing maintenance of the improvements for a period of one year following the completion and acceptance by the City against any defective work or labor done, or defective materials furnished in the performance of this contract with the City of Lake Elsinore. If the Subdivider and the surety fail to install all or any part of the improvements required by this https://lakeelsinore.sharepoint.com/eng/Shared Documents/Engr/Correspondence/TR 31957/Mapping/Monumentation/Construction Agreement_Monumentation_rev.doc 4 agreement within the time set forth herein, or fail to comply with any other obligation contained herein, they shall be jointly and severally liable to the City for any administrative expenses and attorney's fees incurred in obtaining compliance with this agreement and any such expenses and fees incurred in processing any action for damages or for any other remedies permitted by law. It is further understood and agreed that upon default of any obligation hereunder, and at any time after any such default, the City may make written demand upon the Subdivider and surety to immediately remedy the default or complete the work. If said remedial activities or completion of work are not commenced within sixty (60) days after such demand is made and are not thereafter diligently prosecuted to completion and fully completed within one hundred twenty (120) days after the making of such demand (or such other time as may be contained in said demand), the City may then complete or arrange for completion of all remaining work or conduct such remedial activity as in the sole judgement of the City may be required, all at the full expense and obligation of the Subdivider and surety and all without the necessity of giving any further notice to the Subdivider or surety before the City performs or arranges for performance of any remaining work or improvements, and whether or not the Subdivider or surety have constructed any of the required improvements at the time. In the event the City elects to complete or arrange for completion of remaining work and improvements, the City Engineer, upon such election, may require all work by the Subdivider or surety to cease in order to permit adequate coordination by the City for completing any remaining work and improvements not yet completed. It is agreed that all work and improvements done pursuant to this agreement shall conform to the standards applicable at the time work is actually commenced. The Subdivider shall provide security in the amount of One Hundred Nineteen Thousand and Eight Hundred Eighty-Eight and no/100th Dollars ($ 119,880.00) to guarantee the performance of this agreement. In addition, the Subdivider shall provide security in the amount of One Hundred Nineteen Thousand and Eight Hundred Eighty-Eight and no/100th Dollars ($ 119,880.00) to guarantee payment to any contractors, subcontractors, and persons furnishing labor, materials and equipment to them for the performance of the work herein described. Said security shall be in the form of a (corporate surety bonds, cash deposits, etc.) The Subdivider acknowledges and agrees to City regulations governing signs and advertising structures. Subdivider agrees and consents to removal by the City of all signs erected, placed, or situated in violation of any City ordinance governing size, location, or required permits. Removal shall be at the expense of the Subdivider and Subdivider shall indemnify and hold the City free and harmless from any claim or demand arising out of or incurred as a result of such removal, excepting negligent acts or omissions by the City, its agents or employees. Subdivider agrees that said signs may be erected only pursuant to a permit https://lakeelsinore.sharepoint.com/eng/Shared Documents/Engr/Correspondence/TR 31957/Mapping/Monumentation/Construction Agreement_Monumentation_rev.doc 5 issued by the City upon payment of necessary fees or deposits. The Subdivider agrees to provide to the City a Public Liability Insurance Policy, making the City of Lake Elsinore, its officers, agents and employees, additional insured against any injuries or death to any person and property damage. The amount and the insurance company must be approved by the City Engineer. In addition, the Subdivider shall deposit a copy of the Workmen's Compensation Insurance coverage by an approved insurance company and in an amount satisfactory to the City, and as required by law. For purposes of enforcing this agreement, the term "City" includes the City Council, the City Manager, the City Attorney, City Engineer, or any of them, or any of their authorized representatives. In WITNESS WHEREOF, the Subdivider has caused this agreement to be executed this day of , 20 . SIGNED: _________________________________________ (Type Name/Title) FOR: ______________________________________________ (Name of Company on above line) CITY OF LAKE ELSINORE BY: __________________________________________ Grant M Yates, City Manager CITY OF LAKE ELSINORE ATTEST: _________________________________________ Candice Alvarez, City Clerk CITY OF LAKE ELSINORE